SEPT. 28.] THE NEW ZEALAND GAZETTE 2457

If the licensee fails or neglects so to remove the said plant within twelve months after being required so to do, such equipment, machinery, buildings, poles, lines, and other plant shall, without payment of compensation, vest in and become the property of the Crown.

12. SYSTEM OF SUPPLY.

The system of supply shall be as described in paragraph (e) of clause 5 of the Electrical Supply Regulations.

The generating and transmission voltage shall be approximately 220 volts between the terminals.

13. CROWN NOT LIABLE TO PAY COMPENSATION.

Nothing in this license shall be held to impose any liability upon His Majesty the King or upon the Government of New Zealand to pay compensation to any person, corporate body, or local authority by reason of the exercise by the licensee of the authority hereby granted; but the licensee shall be liable for any loss or damage which any person, corporate body, or local authority may sustain as the result of the exercise by the licensee of any of the powers granted by this license.

14. BED OF STREAM NOT LEASED.

Nothing herein shall be held to constitute a lease from the Crown of the bed of the stream shown on the said plan, nor shall the provisions of Part IX of the Property Law Act, 1908, apply to this license.

15. DEFAULT.

If the licensee fails or neglects to observe any of the conditions or obligations imposed by this license, then and in any such case the provisions of clauses 229 and 230 of the Electrical Supply Regulations shall apply to the breach of any such condition or obligation.

16. ALTERATIONS TO WORKS.

In the event of the licensee at any time desiring to make alterations to the works involving a departure from the location or type of construction shown on the approved plans, he shall first submit for the Minister's approval plans showing such new location and/or type of construction as it is proposed to adopt, and with such approval the alterations may be carried out.

17. INSPECTION OF WORKS.

The Inspecting Engineer of the Public Works Department or any other person empowered in that behalf by the Minister shall at all times, both during and after the construction of the works, have free access to and liberty to inspect such works in order to ensure that the provisions of this license are given due effect to:

18. CONTRACT BETWEEN LICENSEE AND CROWN.

This license shall be deemed to constitute a contract as between the licensee and His Majesty the King, and may be enforced by and against either party accordingly.

19. REQUIREMENTS OF THE COOK COUNTY COUNCIL.

Notwithstanding anything hereinbefore contained, the licensee shall not by virtue of these presents be entitled to lay, construct, put up, place, or use the electric lines hereby authorized, except subject to such conditions (not inconsistent with the provisions of this license or of the regulations) as may from time to time be imposed by the Cook County Council.

20. RAILWAYS AND TELEGRAPH DEPARTMENTS' LINES.

The licensee shall rectify to the satisfaction of the Government Railways Board or the Minister of Telegraphs, as the case may be, any interference or disturbance caused by the erection or operation of the licensee's system that affects the satisfactory working of telegraph lines which are the property of the Railways Department or the Telegraph Department and which were erected prior to the licensee's lines.

21. TIME FOR SUBSTANTIAL COMPLETION OF WORKS.

The licensee shall substantially complete the works hereby authorized within a period of one year from the date of this license, or within such further time as the Minister may allow in the event of the work being delayed by strikes, lock-outs, breakdowns, or other unavoidable causes not due to any neglect of the licensee.

22. PURCHASE OF INSTALLATION BY ELECTRIC-POWER BOARD OR CROWN.

Subject to the provisions of the Electric-power Boards Act, 1925, or any Act passed in amendment thereof or in substitution therefor, any Electric-power Board whose district or outer area shall include the area within which are erected the lines described in clause 5 hereof, or the Crown, shall have the right, at any time during the currency of this license, to purchase and take over the licensee's installation at a valuation to be agreed upon between the said Board or the Crown, as the case may be, and the licensee; and, failing such agreement, at a valuation to be fixed by a single arbitrator to be appointed pursuant to the provisions of the Arbitration Act, 1908, and thereupon the Governor-General may by Order in Council revoke this license.

F. D. THOMSON,
Clerk of the Executive Council.
(P.W. 26/1852.)

License authorizing the Kaitangata Coal Company, Limited, of Kaitangata, to erect Electric lines in the Borough of Kaitangata and the County of Bruce.

BLEDISLOEDISLOE, Governor-General.

ORDER IN COUNCIL.

At the Government House at Wellington, this 25th day of September, 1933.

Present:

HIS EXCELLENCY THE GOVERNOR-GENERAL IN COUNCIL.

IN pursuance and exercise of the powers conferred by the Public Works Act, 1928, and of all other powers in anywise enabling him in that behalf, His Excellency the Governor-General of the Dominion of New Zealand, acting by and with the advice and consent of the Executive Council of the said Dominion, doth hereby authorize the Kaitangata Coal Company, Limited, being a company incorporated under the Companies Act, 1908, and having its registered office at Kaitangata (hereinafter referred to as "the licensee"), to lay, construct, put up, place, and use the electric lines described in the Schedule hereto on the following conditions.

CONDITIONS.

1. PURPOSE OF LINES.

THE said lines may be used for lighting, power, and heating purposes.

2. LICENSE TO BE SUBJECT TO REGULATIONS.

The license hereby conferred is subject to compliance by the licensee with the Electrical Wiring Regulations, 1927, the Electrical Supply Regulations, 1927, and with all regulations made or to be made in amendment thereof or in substitution therefor.

3. SYSTEM OF SUPPLY.

The system of supply shall be the system described in paragraph (e) of clause 5 of the said regulations.

4. GENERATING VOLTAGE.

Electrical energy shall be generated at a pressure of 6,600 volts between phases, and may be transformed to 3,300 volts between phases or to 440 volts between phases for the licensee's own purposes.

5. DURATION OF LICENSE.

Unless sooner lawfully determined this license shall continue in force in respect of the lines described in clause (1) of the Schedule hereto for a period of twenty-one years from the date hereof, and in respect of the lines described in clause (2) of the said Schedule, for a period of two years commencing on the 1st day of November, 1933.

6. PURCHASE OF INSTALLATION BY ELECTRIC-POWER BOARD OR CROWN.

Subject to the provisions of the Electric-power Boards Act, 1925, or any Act passed in amendment thereof or in substitution therefor, any Electric-power Board duly constituted in terms of the Electric-power Boards Act, 1925, or any Act passed in amendment thereof or in substitution therefor, if its district or outer area shall include the area in which are erected the lines described in the Schedule hereto, or the Crown, shall have the right, at any time during the currency of this license, to purchase and take over the licensee's installation at a valuation to be agreed upon between the said Board or the Crown, as the case may be, and the licensee; and, failing such agreement, at a valuation to be fixed by a single arbitrator to be appointed pursuant to the provisions of the Arbitration Act, 1908, and thereupon the Governor-General may by Order in Council revoke this license.